Welcome to DeckWorks. By accessing or using this website, requesting a quote, submitting a contact form, communicating with our team, or engaging our services, you agree to be bound by these Terms and Conditions. If you do not agree with these terms, please do not use this website.
1. Company Information
DeckWorks provides residential deck, patio, and outdoor living construction services throughout Omaha, Lincoln, and surrounding Nebraska and Iowa communities.
These Terms and Conditions govern your use of our website and services.
2. Website Use
You agree to use this website only for lawful purposes and in a manner that does not infringe upon the rights of others or restrict their use of the website.
You may not:
- Attempt to gain unauthorized access to our systems or website.
- Use the website for fraudulent or unlawful activities.
- Introduce viruses, malware, or harmful code.
- Copy, reproduce, or distribute website content without written permission.
We reserve the right to restrict or terminate access to users who violate these terms.
3. Estimates and Proposals
Any estimate, quote, proposal, or pricing information provided by DeckWorks is subject to change until a written agreement has been executed by both parties.
Project pricing may be affected by:
- Material cost fluctuations
- Site conditions
- Permit requirements
- Design modifications
- Customer-requested changes
A proposal does not constitute a binding contract until accepted and signed by both parties.
4. Construction Services
Project timelines are estimates only and may be affected by circumstances beyond our control, including but not limited to:
- Weather conditions
- Material availability
- Labor shortages
- Permit delays
- Utility delays
- Site accessibility issues
- Customer-requested changes
DeckWorks will make reasonable efforts to complete projects within the estimated timeframe but does not guarantee completion dates unless expressly stated in a written agreement.
5. Customer Responsibilities
Customers agree to:
- Provide accurate information regarding their property and project requirements.
- Ensure reasonable access to the project site.
- Obtain approvals from homeowners associations when required.
- Secure pets and maintain safe site access during construction.
- Make payments according to the agreed-upon payment schedule.
Failure to meet these obligations may result in project delays or additional charges.
6. Payments
Payment terms will be outlined within each project agreement.
Late payments may result in:
- Project delays
- Suspension of work
- Additional fees as permitted by law
All deposits are subject to the terms outlined in the signed project agreement.
7. Change Orders
Any changes requested after project approval may require a written change order.
Change orders may affect:
- Project cost
- Completion timeline
- Material selections
- Construction scope
No additional work will be performed until change orders have been approved.
8. Warranty Disclaimer
Specific workmanship warranties, if offered, will be outlined in your project agreement.
Except as expressly stated in writing, all services and website content are provided “as is” without warranties of any kind, whether express or implied.
DeckWorks disclaims all implied warranties including merchantability, fitness for a particular purpose, and non-infringement to the fullest extent permitted by law.
9. Limitation of Liability
To the maximum extent permitted by law, DeckWorks shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising from:
- Use of this website
- Delays in project completion
- Material shortages
- Third-party services
- Loss of profits
- Property conditions beyond our control
Our total liability shall not exceed the amount paid by the customer for the services directly giving rise to the claim.
10. Third-Party Links
This website may contain links to third-party websites for informational purposes.
DeckWorks is not responsible for the content, policies, security, or practices of any third-party website.
Use of third-party websites is at your own risk.
11. Intellectual Property
All content on this website, including but not limited to:
- Logos
- Images
- Text
- Graphics
- Videos
- Designs
- Layouts
- Tools and Calculators
are the sole property of DeckWorks or its licensors and are protected by applicable intellectual property laws.
Unauthorized use is prohibited.
12. SMS Messaging & A2P Compliance
By submitting your information through our website forms, requesting a quote, scheduling a consultation, or otherwise providing your mobile phone number, you expressly consent to receive calls and text messages from DeckWorks regarding:
- Appointment scheduling
- Project updates
- Estimate follow-ups
- Customer service communications
- Service-related notifications
- Promotional offers and marketing communications (where applicable)
Message Frequency
Message frequency may vary depending on your interactions with our company and the status of your project.
Message and Data Rates
Message and data rates may apply according to your mobile carrier’s plan.
Opt-Out Instructions
You may opt out of SMS communications at any time by replying:
STOP
After opting out, you will receive a confirmation message and no further marketing text messages will be sent.
Help Instructions
For assistance, reply:
HELP
or contact us directly through our website.
Consent
Consent to receive text messages is not a condition of purchasing services from DeckWorks.
Carrier Disclaimer
Mobile carriers are not liable for delayed or undelivered messages.
13. Electronic Communications
By contacting us electronically, submitting forms, or communicating through our website, you consent to receive communications electronically, including notices, agreements, invoices, and project-related updates.
14. Privacy
Your use of this website is also governed by our Privacy Policy.
Please review our Privacy Policy to understand how we collect, use, and protect your information.
15. Indemnification
You agree to defend, indemnify, and hold harmless DeckWorks, its owners, employees, contractors, affiliates, and representatives from any claims, damages, losses, liabilities, and expenses arising from:
- Your use of this website
- Violation of these Terms and Conditions
- Violation of any applicable laws or regulations
16. Governing Law
These Terms and Conditions shall be governed by and construed in accordance with the laws of the State of Nebraska, without regard to conflict of law principles.
Any disputes arising from these terms shall be resolved in the courts located within Nebraska.
17. Changes to These Terms
DeckWorks reserves the right to update or modify these Terms and Conditions at any time.
Updates will be posted on this page with a revised effective date.
Continued use of the website constitutes acceptance of any revised terms.
18. Contact Information
If you have questions regarding these Terms and Conditions, please contact us through our Contact page.
